Architects are licensed professionals trained in the art and science of building. Architects design the overall aesthetic and look of buildings and other structures, and ensure that the buildings are functional, safe, and economical and suit the needs of the people who use them. Architects consider all these factors when they design buildings and other structures. Architects provide professional services to individuals and organizations planning a construction project. They may be involved in all phases of development, from the initial discussion with the client through the entire construction process.
This form is a generic example that may be referred to when preparing such a form for your particular state. It is for illustrative purposes only. Local laws should be consulted to determine any specific requirements for such a form in a particular jurisdiction.
The Tennessee Contract for Construction of a Building with Architect as Owner's Representative during the Construction Period is a legal agreement entered into between an owner and an architect in the state of Tennessee. This contract outlines the terms and conditions for the construction of a building, where the architect assumes the role of the owner's representative throughout the construction process. Key elements of the Tennessee Contract for Construction of a Building with Architect as Owner's Representative may include: 1. Scope of Work: This section outlines the specific architectural services that the architect will provide during the construction period. It may include tasks such as overseeing the design process, coordinating with contractors and subcontractors, reviewing construction plans, and ensuring compliance with building codes and regulations. 2. Project Schedule: The contract may include a detailed timeline for the construction project, including start and completion dates for various milestones, inspections, and final completion. 3. Compensation: This section defines the payment terms for the architect's services. It may outline a lump sum fee, hourly rate, or a percentage of the overall construction cost. The contract may also specify any additional expenses reimbursed to the architect, such as travel or printing costs. 4. Change Orders: This section addresses how changes or modifications to the original construction plans will be handled. It outlines the process for requesting and approving change orders, including potential cost adjustments and time extensions. 5. Dispute Resolution: The contract may include a clause that outlines the procedures for resolving any disputes that may arise during the construction period. This could involve negotiation, mediation, or arbitration, depending on the agreed-upon method of dispute resolution. 6. Termination: This section outlines the conditions under which either party can terminate the contract before the completion of the construction project. It may specify the required notice period and any applicable fees or penalties. 7. Insurance and Liability: The contract may require the architect to maintain professional liability insurance and provide proof of coverage during the construction period. It may also outline the responsibilities and liabilities of both the owner and architect in the event of injuries, damages, or other unforeseen incidents. Different types or variations of the Tennessee Contract for Construction of a Building with Architect as Owner's Representative may include various project-specific requirements or customized terms based on the nature of the construction project. These could include contracts for residential buildings, commercial structures, government facilities, educational institutions, healthcare facilities, and more.
