This state specific form addresses issues for subcontract work including: identifying the parties, identifying the jobsite, describing the work, scheduling the work, payment amount, payment schedule, change orders, contractor’s delay in commencing work, late payments, dispute resolution, excusable delay, concealed conditions, insurance, and contract interpretation.
Cape Coral Florida Subcontractor's Agreement
State:
Florida
City:
Cape Coral
Control #:
FL-00481-CPK
Format:
Word
Instant download
Description
Free preview
How to fill out Florida Subcontractor's Agreement?
Are you searching for a dependable and cost-effective provider of legal documents to obtain the Cape Coral Florida Subcontractor's Agreement? US Legal Forms is your ultimate answer.
Whether you require a simple contract to establish rules for living with your partner or a collection of documents to facilitate your separation or divorce through the legal system, we have you covered.
Our platform offers over 85,000 current legal document templates for individual and business purposes. All templates available are not generic and are tailored based on the regulations of distinct states and regions.
To acquire the document, you must Log In to your account, locate the necessary form, and click the Download button adjacent to it.
If the form is not appropriate for your particular situation, start the search anew.
Now you can register your account, select the subscription plan, and complete your payment. Once the payment is processed, download the Cape Coral Florida Subcontractor's Agreement in any available format. You can revisit the website whenever needed and redownload the document at no additional cost.
- Please note that you can retrieve your previously purchased form templates at any time from the My documents section.
- Is this your first visit to our site? No problem.
- You can effortlessly create an account, but ensure to do the following beforehand.
- 1. Verify if the Cape Coral Florida Subcontractor's Agreement aligns with the laws of your state and locality.
- 2. Review the details of the form (if available) to determine its applicability.
Form popularity
FAQ
Know your deadline to file a Florida mechanics lien Lien claims can be recorded at any time during the construction project or within 90 days after the last day you furnished labor or materials to the property.
Liens are valid for five years from the original filing date. Florida law allows judgment liens to be filed a second time to extend the lien's validity five more years. (See s. 55.201-55.209, F.S.)
Filing your own lien in Florida has varying costs. Depending on the supporting documentation and length of your lien paperwork, it can cost as little as $10 for the first page and an additional $8.50 for each additional page.
A Florida mechanics lien must be in the proper format and filed in the county recorder's office in the county where the property is located within the required timeframe. To record a lien in Florida, you will need to bring your completed Claim of Lien form to the recorder's office and pay the filing fee.
A lien is valid for one year, unless a lienor files a lawsuit to enforce the lien prior to the expiration of the year. An owner has a right to file a Notice of Contest of Lien during the one-year period. Upon the filing of a Notice of Contest of Lien, a lienor must file a lawsuit to enforce the lien within 60 days.
FLORIDA'S CONSTRUCTION LIEN LAW ALLOWS SOME UNPAID CONTRACTORS, SUBCONTRACTORS, AND MATERIAL SUPPLIERS TO FILE LIENS AGAINST YOUR PROPERTY EVEN IF YOU HAVE MADE PAYMENT IN FULL. UNDER FLORIDA LAW, YOUR FAILURE TO MAKE SURE THAT WE ARE PAID MAY RESULT IN A LIEN AGAINST YOUR PROPERTY AND YOUR PAYING TWICE.
In Florida, the deadline to file a mechanics lien is 90 days from last furnishing labor or materials to the project. The claimant must serve a copy of the lien on the property owner within 15 days after filing the lien.
FLORIDA'S CONSTRUCTION LIEN LAW ALLOWS SOME UNPAID CONTRACTORS, SUBCONTRACTORS, AND MATERIAL SUPPLIERS TO FILE LIENS AGAINST YOUR PROPERTY EVEN IF YOU HAVE MADE PAYMENT IN FULL. UNDER FLORIDA LAW, YOUR FAILURE TO MAKE SURE THAT WE ARE PAID MAY RESULT IN A LIEN AGAINST YOUR PROPERTY AND YOUR PAYING TWICE.
If you want to remove a lien from your property, you need to do one of two things: 1) have the contractor record a release of the lien or 2) file an appeal to have the lien released.
To attach a lien, the creditor must record the judgment with the county recorder in any Florida county where the debtor owns real estate now or may own real estate in future. For liens on personal property, the creditor files the judgment with the Florida Department of State.
