US Legal Forms
Ohio Request for Notice of Commencement - Individual

Ohio Request for Notice of Commencement - Individual

Category:

Liens - Construction - Mechanics

State:

Ohio

Control #:

OH-10-09

Format:

Instant download

Description

Ohio Revised Code sections 1311.04 (D), (E), and (F) require that a subcontractor, materialman, or laborer who requests to be provided with a copy of the Notice of Commencement be provided with a copy of said Notice within ten days after submitting a request in writing to either the owner, part-owner, lessee, contractor, or subcontractor.

Definition and meaning

The Ohio Request for Notice of Commencement - Individual is a legal document used by subcontractors, material suppliers, or laborers to formally request a copy of the Notice of Commencement from the owner or lessee of a property undergoing improvements. This form is essential for ensuring that all parties involved in construction or renovation projects are informed about the securing of their interests, as it provides necessary documentation to protect their rights under Ohio law.

How to complete a form

To complete the Ohio Request for Notice of Commencement - Individual, follow these steps:

Fill in your personal details: Include your name and address at the top of the form.
Provide the property information: Specify the address of the property being improved.
Indicate the type of request: Clearly state your request for a copy of the Notice of Commencement.
Sign the form: Ensure you sign and date the document, followed by a witness if needed.

Always double-check that all fields are correctly filled out before submission to avoid delays.

Who should use this form

The Ohio Request for Notice of Commencement - Individual should be used by any subcontractor, material supplier, or laborer who is not an original contractor but wants to ensure they receive information regarding commencement of work on a property. This form is particularly useful for individuals who may be financially invested in or providing services to a construction project.

Legal use and context

According to Ohio Revised Code §1311.04(D), (E), and (F), this form serves as a legal means for subcontractors and suppliers to secure their right to be notified about the commencement of work on a property. It ensures that maintainers of the property, such as owners and contractors, are obligated to inform requesters, thereby safeguarding their interests in the event of disputes or claims regarding lien rights.

Key components of the form

The Ohio Request for Notice of Commencement - Individual includes several important sections:

Requester’s Information: Name, address, and contact information of the person requesting the notice.
Property Information: The address of the property where work is taking place.
Signature Section: Space for the requester to sign and date the form.
Notary Section: Requires acknowledgment before a notary public, verifying the identity and signature of the requester.

What documents you may need alongside this one

When submitting the Ohio Request for Notice of Commencement - Individual, you may also need the following documents:

A copy of any contracts related to the work being performed.
Identification documents to verify your identity.
Any prior correspondence related to the property or project.

Having these documents on hand can help streamline the process and support your request.

Common mistakes to avoid when using this form

To ensure your request is processed smoothly, watch out for these common errors:

Incomplete Information: Ensure all required fields are filled out completely.
Incorrect Signatures: Make sure that your signature is clear and matches your name as it appears on the form.
Failure to Notarize: Don’t forget to have the form notarized, as this is essential for its validity.

By avoiding these mistakes, you can increase the likelihood of a successful filing.

Order Granting Criminal Defendant's Motion to Modify Release Agreement

View this form

Authority for Release of Information for US Agency for International Development

View this form

Acknowledgement of Certain Internal Confidentiality Agreements Prohibition of Applicant

View this form

Bylaws of a Church

View this form

Compliance Certificate for Contractor Document Retention and Production Injury and Illness Prevention Program

View this form

Assignment of Lease from Lessor with Notic...

View this form

Georgia Standby Temporary Guardian Legal D...

View this form

Do Not Resuscitate Request - DNR

View this form

Creditors Garnishment Report

View this form

Letter Sample Request for Information

View this form

Motion to Transfer for Amount in Excess of...

View this form

Sample Letter for Decline to Give Advice

View this form

Turnkey Hardware and Software Agreement

View this form

Release of Donor or Real Property, Waiver ...

View this form

Complaint For Negligence - Fraud and Decep...

View this form

How to fill out Ohio Request For Notice Of Commencement - Individual?

When it comes to submitting Ohio Request for Notice of Commencement - Individual, you almost certainly think about an extensive procedure that requires getting a ideal form among numerous very similar ones and after that having to pay an attorney to fill it out to suit your needs. Generally speaking, that’s a slow-moving and expensive option. Use US Legal Forms and pick out the state-specific document within just clicks.

If you have a subscription, just log in and then click Download to find the Ohio Request for Notice of Commencement - Individual sample.

In the event you don’t have an account yet but want one, keep to the point-by-point guide below:

Be sure the file you’re saving is valid in your state (or the state it’s required in).
Do this by looking at the form’s description and also by clicking the Preview function (if readily available) to find out the form’s information.
Simply click Buy Now.
Select the appropriate plan for your budget.
Subscribe to an account and choose how you want to pay: by PayPal or by card.
Save the file in .pdf or .docx file format.
Find the file on the device or in your My Forms folder.

Professional legal professionals work on creating our templates to ensure after downloading, you don't have to worry about editing and enhancing content outside of your personal info or your business’s info. Join US Legal Forms and get your Ohio Request for Notice of Commencement - Individual document now.

Form popularity

FAQ

Name and address of owner. Name and address of original contractor. Name and address of the party who hired you. Description of the property location. Date of first furnishing services to the project. Name and address of the lien claimant.

The Notice of Commencement shall be recorded in the office of the Clerk where the real property is located. A certified copy of the Notice of Commencement must be posted on the property. The property owner must sign the Notice of Commencement and no one else may be permitted to sign in his or her stead.

Ohio requires that a Notice of Commencement be filed: in the office of the county recorder for each county in which the real property to be improved is located, that the owner, part owner, lessee, or designee shall post and maintain posted a copy of the notice of commencement in a conspicuous place on the real

The Notice of Commencement (sometimes called a Notice of Project Commencement, a Notice of Contract, or Affidavit of Commencement) is most simply explained as a document that formally designates the beginning of a construction project.

Under Ohio Revised Code 1311.04, an owner of real property must serve notice on any potential lien claimant. The form of notice is called a Notice of Commencement. The purpose of the Notice of Commence is to protect property owners and provide notice to any potential lien claimant that the project is commencing.

The owner or lessee contracting for the improvements must record a Notice of Commencement in the office of the register of deeds for each county in which the real property to be improved is located. M.C.L. 570.1108(1).

Is a Notice of Commencement required In Georgia? Yes. Georgia requires that property owners or the owner's agent or the general contractor records a notice of commencement on all construction jobs in the state.

The legal description of the real property. The basic information and address of the owner (or lessee) The name and address of the fee owner of the real property, if the person contracting for the improvement is a land contract vendee or lessee.

Trusted and secure by over 3 million people of the world’s leading companies

Request for Notice of Commencement - Individual

Note: This summary is not intended to be an all inclusive summary of the law of construction liens in Ohio, but does contain basic and other provisions.

Definitions relative to Ohio Mechanics' Liens as used in sections 1311.01 to 1311.22 of the Revised Code:

(A) "Owner," "part owner," or "lessee" includes all the interests either legal or equitable, which such person may have in the real estate upon which the improvements are made, including the interests held by any person under contracts of purchase, whether in writing or otherwise.

(B) "Materialman" includes any person by whom any materials are furnished in furtherance of an improvement.

(C) "Laborer" includes any mechanic, workman, artisan, or other individual who performs labor or work in furtherance of any improvement.

(D) "Subcontractor" includes any person who undertakes to construct, alter, erect, improve, repair, demolish, remove, dig, or drill any part of any improvement under a contract with any person other than the owner, part owner, or lessee.

(E) "Original contractor," except as otherwise provided in section 1311.011 [1311.01.1] of the Revised Code, includes a construction manager and any person who undertakes to construct, alter, erect, improve, repair, demolish, remove, dig, or drill any part of any improvement under a contract with an owner, part owner, or lessee.

(F) "Construction manager" means a person with substantial discretion and authority to manage or direct an improvement, provided that the person is in direct privity of contract with the owner, part owner, or lessee of the improvement.

(G) "Notice of commencement" means the notice specified in section 1311.04 of the Revised Code.

(H) "Notice of furnishing" means the notice specified in section 1311.05 of the Revised Code.

(I) "Materials" means all products and substances including, without limitation, any gasoline, lubricating oil, petroleum products, powder, dynamite, blasting supplies and other explosives, tools, equipment, or machinery furnished in furtherance of an improvement.

(J) "Improvement" means constructing, erecting, altering, repairing, demolishing, or removing any building or appurtenance thereto, fixture, bridge, or other structure, and any gas pipeline or well including, but not limited to, a well drilled or constructed for the production of oil or gas; the furnishing of tile for the drainage of any lot or land; the enhancement or embellishment of real property by seeding, sodding, or the planting thereon of any shrubs, trees, plants, vines, small fruits, flowers, or nursery stock of any kind; and the grading or filling to establish a grade.

(K) "Wages" means the basic hourly rate of pay and all other contractually owed benefits.

(L) "Home construction contract" means a contract entered into between an original contractor and an owner, part owner, or lessee for the improvement of any single- or double family dwelling or portion of the dwelling or a residential unit of any condominium property that has been submitted to the provisions of Chapter 5311. of the Revised Code; an addition to any land; or the improvement of driveways, sidewalks, swimming pools, porches, garages, carports, landscaping, fences, fallout shelters, siding, roofing, storm windows, awnings, and other improvements that are adjacent to single- or double family dwellings or upon lands that are adjacent to single- or double family dwellings or residential units of condominium property, if the dwelling, residential unit of condominium property, or land is used or is intended to be used as a personal residence by the owner, part owner, or lessee.

(M) "Home purchase contract" means a contract for the purchase of any single- or double family dwelling or residential unit of a condominium property that has been subjected to the provisions of Chapter 5311. of the Revised Code if the purchaser uses or intends to use the dwelling, a unit of a double dwelling, or the condominium unit as his personal residence.

(N) "Lending institution" means any person that enters into a contract with the owner, part owner, purchaser, or lessee to provide financing for a home construction contract or a home purchase contract, which financing is secured, in whole or in part, by a mortgage on the real estate upon which the improvements contemplated by the home construction contract are to be made or upon the property that is the subject of the home purchase contract, and that makes direct disbursements under the contract to any original contractor or the owner, part owner, purchaser, or lessee.

(O) "Original contractor" includes any person with whom the owner, part owner, lessee, or purchaser under a home purchase contract or a home construction contract has directly contracted.

Who My File a Lien?

Pursuant to Ohio statutes, a contractor, subcontractor, or materialman who has provided labor or materials to a construction project may file a lien against the property for the value of the labor performed or materials supplied by filing an Affidavit of Mechanic's Lien. A lien may not be obtained against property when the party claiming the lien has been paid in full before the property owner has received a copy of the lien claimant's Affidavit of Mechanic's Lien. O.R.C. 1311.01(B).

How Long Does a Lien Claimant Have to File a Lien?

An Affidavit for a Mechanic's Lien must be filed within sixty days from the last day of work performed by the party claiming the lien, if the project is a one or two family residential dwelling. Otherwise, the lien claimant has seventy-five (75) days to file for a lien. An exception is liens involving oil and gas leases, which may be filed within one hundred and twenty (120) days. O.R.C.1311.06(B).

What is a Notice of Commencement?

Prior to beginning work on a project which may give rise to a mechanic's lien, the property owner should file a Notice of Commencement with the county recorder in the county where the property is located. A Notice of Commencement is an affidavit which describes the improvements to be made to the property, the legal description of the property, and the names and addresses of all parties involved in the contract, along with some statutory notices, that put potential buyers or lenders on notice that improvements that may cause a lien to be filed are being made. O.R.C. 1311.04(A)(1).

A subcontractor, materialman, or laborer, may make a written request for a copy of the Notice of Commencement, to which the owner is obligated to respond within ten days. O.R.C. 1311.04(D).

What is a Notice of Furnishing?

As a counterpart to the owner's Notice of Commencement is the Notice of Furnishing that must be served by a subcontractor or materialsman on the property owner. A Notice of Furnishing serves to put the owner on notice that the party furnishing labor and materials may be entitled to a lien against the property. O.R.C. 1311.05(A)

If the Notice to Commencement has been filed, a party who wants to preserve their right to file a lien must file their Notice of Furnishing within twenty-one days of the Notice of Commencement being served. O.R.C. 1311.04(I).

How is a Lien Released?

When an Affidavit has been filed and the lien claimant has subsequently been paid, the property owner may file an affidavit attesting to the fact that the lien has been satisfied. The lienholder has thirty days from receipt of this affidavit to file a lien release or be subject to pay the property owner damages as a result. O.R.C. 1311.01(B)(3).

Lending institutions may not release funds to a contractor until that contractor has filed an affidavit stating that the contractor has paid all subcontractors, laborers, and materialmen in full, and that there are no further claims pending against the project. A property owner may issue written demand that the contractor issue this affidavit and may withhold payment until the affidavit is received. O.R.C. 1311.01(B)(4).

If there is a dispute between subcontractors and the principal contractor regarding payment, such that the subcontractor will not release his lien, under Ohio statutes, the property owner is entitled to withhold payment to the principal contractor in the amount of the lien. In response, the principal contractor and lending institution may demand that the lien holder provide them with information regarding the amount of the lien and the dates upon which work was performed. The owner or lending institution may only release payment to the original contractor when the lien holder has given notice that he has been paid, the subcontractor issues a lien release, the original contractor provides a bond, or the time under which a lien may be filed has expired. O.R.C. 1311.01(B)(8).

How Else May a Property Owner Respond to a Lien?

After a lien has been filed, a property owner may serve a Notice to the Lien holder to Commence Suit. Within thirty days of serving the notice the property owner must file the notice with an affidavit indicating how service was accomplished. The lien holder has sixty days after being served to file suit or his lien will be rendered void. O.R.C. 1311.11(B)(3)