Maine Contractor's Schedule Sheet

State:
Multi-State
Control #:
US-00469-CPK
Format:
Word
Instant download

Description

This easily fillable form assists a general contractor in the planning and scheduling of the various trades involved in a specific project. The form is designed to help track the completion of certain phases of the project.

Maine Contractor's Schedule Sheet is a comprehensive document that is widely used in the construction industry in the state of Maine. It is specifically designed to efficiently organize and manage the complex schedules of contractors involved in various construction projects. This sheet serves as a vital tool for contractors to plan, track, and coordinate all project activities, ensuring smooth project execution and timely completion. The Maine Contractor's Schedule Sheet typically includes a range of important information. It outlines project details such as the name and location of the construction site, project owner, contract number, and project start and end dates. Additionally, it provides space for the contractor to list all the tasks and activities involved in the project, along with their corresponding start and finish dates. This helps in creating a clear timeline of activities and milestones, enabling effective project management. Moreover, the schedule sheet also incorporates sections for tracking progress and recording actual start and end dates of completed tasks. This allows the contractor to compare the planned schedule with the actual progress, identify potential delays or issues, and make necessary adjustments to the project plan. Furthermore, the sheet may include additional columns for documenting resources, such as labor, equipment, and materials required for each task. The Maine Contractor's Schedule Sheet can be customized to meet the specific needs of different construction projects. Variations of the schedule sheet can include different formats or layouts, depending on the preferences and requirements of contractors and project owners. For instance, some contractors may prefer a Gantt chart-style schedule sheet, while others may opt for a more traditional table-style format. Regardless of the format, the purpose of all types of Maine Contractor's Schedule Sheets remains the same — to provide a comprehensive and structured outline of project timelines and activities. In conclusion, the Maine Contractor's Schedule Sheet is a versatile and indispensable tool for contractors in Maine's construction industry. It enables effective coordination, tracking of progress, and timely completion of construction projects. By utilizing this sheet, contractors can ensure efficient allocation of resources, optimize project planning, and minimize delays, ultimately contributing to successful project outcomes.

How to fill out Maine Contractor's Schedule Sheet?

Selecting the ideal legal document template can be quite challenging. Certainly, there are many templates available online, but how can you find the legal form you require.

Utilize the US Legal Forms website. The service offers a multitude of templates, such as the Maine Contractor's Schedule Sheet, which can be employed for business and personal purposes.

All of the forms are evaluated by experts and fulfill state and federal regulations.

Once you are sure the form is suitable, select the Buy now button to obtain the form. Choose the pricing plan you desire and enter the required information. Create your account and complete your purchase using your PayPal account or credit card. Opt for the file format and download the legal document template to your device. Complete, edit, print, and sign the acquired Maine Contractor's Schedule Sheet. US Legal Forms is the largest repository of legal forms where you can find a variety of document templates. Take advantage of the service to download professionally crafted documents that adhere to state requirements.

  1. If you are currently registered, Log In to your account and click on the Download button to locate the Maine Contractor's Schedule Sheet.
  2. Use your account to browse the legal forms you have previously purchased.
  3. Visit the My documents tab in your account to obtain another copy of the documents you need.
  4. If you are a new user of US Legal Forms, here are simple guidelines to follow: First, make sure you have selected the correct form for your city/state.
  5. You can review the form using the Preview button and read the form description to confirm it is the right one for you.
  6. If the form does not fulfill your requirements, utilize the Search field to find the appropriate form.

Form popularity

FAQ

However, the general format to expect will include columns with the following details:The description of each item of work.The total cost for each item.What you've been paid to date on the work, from prior billing periods.The percentage of the work that's been completed.Your costs for the current billing period.More items...?

What Should a Schedule of Values Include?Project name and number.Name of the prime or general contractor.Application number and date.Work item numbers.Description of work items.Total value of each item.Percentage of work completed.Value of work completed for past and current periods.More items...?

A schedule of values is a comprehensive list of the work that needs to get done on a construction job, and it shows the payment values attributed to each item. This document explains each step of a contract in chronological order S.O.V. is a common name for this itemized list.

A schedule of values commonly referred to as SOV is a comprehensive documented list of work that was done on a particular project. SOV's are an essential part of every construction project.

The contractor must collect and remit sales tax based on the sale price of the items it sells at retail.

In the state of Maine, services are not generally taxable. While most services are exempt, there are a few exceptions. For example, a service who's work includes creating or manufacturing a product is very likely considered to be taxable, and thus you would most likely have to pay sales tax on the service.

Sales and use tax rate. The state of Maine has several sales and use tax rates. The general rate that applies to most sales of tangible personal property and services is 5 percent.

A Schedule of Values, or SOV, is a list of every work item on a project, along with each item's value or cost. This comprehensive work list represents the entire construction project and the entire contract price, from beginning to end.

What should be included in a Contractor Agreement?Statement of Relationship.Project Description.Payment and Billing Terms.Responsibilities of Each Party.Project Timeline and Deadlines.Termination Conditions.Nondisclosure Terms, and Confidentiality and Non-Compete Clauses.

The following services are subject to the Service Provider Tax in MaineAncillary Services.Rental of Video Media and Video Equipment.Rental of Furniture, Audio Media and Equipment pursuant to a Rental-Purchase Agreement.Telecommunications Services.Installation, Maintenance or Repair of Telecommunications Equipment.More items...

Interesting Questions

More info

This form is a sample jury instruction wherein the court instructs the jury that theA resident of Maine is accused of murder and requests a grand jury ... To appear on the Efficiency Maine website, please complete this form andMaine program, Vendor is a direct contractor to the customer.When negotiating a construction contract, most contractors use either a "lump-sum" contract or a "time and material" contract. While other types of contracts ... Notice to ContractorsSealed Bids addressed to the Western Maine Transportation Services andplease fill out and email the attached RFI Form to ... A general contractor, main contractor or prime contractor is responsible for the day-to-day oversight of a construction site, management of vendors and ... Customer must submit new construction application to MWCNewService@mainewater.com; Customer must submit design drawings to MWC; MWC to complete an onsite ... General: Form WH-347has been made available for the convenience of contractors and subcontractors required by their Federal or Federally-aided ... Cianbro, a 100 percent employee-owned construction company, offers award-winningCianbro is adept at completing projects on schedule and within budget. Out-of-state contractors or subcontractors doing business in Massachusetts areSection 1 of the Guarantee Bond Form must be filled out ... Notice to Contractors Sheet N-1 and N-2 are deleted and replaced with Notice tothe Contractor sufficient time to complete the work in a.

0.12) Adobe Reader 7.0 or higher is required in order for this to work. The file is currently 3 MB in size. More Information. Dealing With Your City/Town Find the address, street, or route number of the business you're going to. Click on the business name to see a list of other businesses in the particular area. If you know the address of the business only — you can still search by business number. If you are looking for the address of a business, use either the address or business number combination above. You can also use this Google Map to find the address of a business. What Does the Google Map Look Like? Click on a business name or the area name to see the Google Map of businesses in the neighborhood. If you would like to save the page, click on the blue button at the bottom right side of the Google Map. If you would like to zoom in, click on the middle button at the bottom of the Google Map. If you would like to zoom out, click in the middle of the Google Map.

Trusted and secure by over 3 million people of the world’s leading companies

Maine Contractor's Schedule Sheet