Film Contract For Actors In Broward

• Category: Contracts - Productions
• State: Multi-State
• County: Broward
• Control #: US-00034DR
• Format: Word; Rich Text

Description

The Film Contract for Actors in Broward outlines the agreement between a producer and a client for the production of a motion picture. It specifies key features including the film's description, length, script details, technical advice, and ownership of copyright, ensuring that clients retain rights to the finished product. The contract also addresses producer compensation, outlining payment terms linked to milestone completions, and stipulates the completion date with provisions for delivery and potential delays. The form elaborates on the responsibilities for storing the negative film, handling liquidated damages for delays, and the process for ordering additional prints post-completion. The included clauses ensure clarity for both parties concerning modifications, arbitration for disputes, and compliance with applicable laws, enhancing its utility in securing a professional relationship. This form is vital for attorneys, partners, owners, associates, paralegals, and legal assistants, as it provides a structured template to navigate the complexities of film contracts, ensuring that all essential terms are covered while minimizing the risks associated with film production.